A recent Supreme Court warning to always read the contract should be taken to heart by lawyers as well as signatories to contracts. Parties are free to allocate risk as they see fit, and the courts will uphold such clauses.
The age-old adage for children about to sit exams is to ‘always read the question’. Two recent decisions from the courts would suggest that construction lawyers would do well to heed that advice too – they provide a useful reminder that, before getting embroiled in a
dispute, it is important to ‘always read the contract’.
First, in August this year, in the final instalment of the MT Højgaard v E.ON saga, Lord Neuberger in the Supreme Court reminded construction lawyers that the whole of the contract needs to be considered (see MT Højgaard A/S v E.On Climate & Renewables UK Robin Rigg East Ltd  UKSC 59). It is not possible simply to ignore parts of the contract because they are ‘tucked away’ in the technical documents.
Now, Fraser J, in the Technology and Construction Court (TCC), has delivered a forceful judgment in North Midland Building Ltd v Cyden Homes Ltd  EWHC 2414 (TCC) (2 October 2017), in which he held that the parties to a building contract are free to allocate the risk of concurrent delay to the works, and any such clauses will be upheld by the courts.
Please click here to read the full article.
This article was first published in Construction Law Vol 28 No 10, December 2017
The contents of this publication are for reference purposes only and may not be current as at the date of accessing this publication. They do not constitute legal advice and should not be relied upon as such. Specific legal advice about your specific circumstances should always be sought separately before taking any action based on this publication.
© Herbert Smith Freehills 2021